top of page
Copper Creek Contractors estimate request in Champaign, Illinois

Win a FREE Roof

Get ready for the ultimate giveaway at the Illinois Football Spring Game! Join Copper Creek Contractors at our tailgate event for a chance to win a FREE roof. Simply fill out the form below or in person at the event, and you could be the lucky winner.

 

Don't miss out – the winner will be selected on April 26th, 2024! See disclaimer below.

Do you own your home?
Do you have any pre-existing structural damage or leaks?
Do you currently have an open insurance claim on your home?

Thanks for entering!

DISCLAIMER:

The winner will receive a full shingle replacement to be installed by Copper Creek Contractors. The prize includes the replacement of shingles and all roof accessories. The winner also will receive up to five sheets of OSB if needed to properly install the shingles.

 

Although not required to receive an entry, contestants will receive an additional entry if they like, follow, and share the official Copper Creek Contractors Facebook page on their Facebook account.

 

Acceptance: All orders are subject to acceptance by COPPER CREEK Contractors. This Agreement is not binding on (COPPER CREEK) unless accepted by COPPER CREEK, and if such acceptance is declined by COPPER CREEK for any reason, all deposit monies paid will be refunded in full and COPPER CREEK shall not be liable to have any further responsibility.

 

Any and all Salvage and scrap materials being removed or replaced belong to COPPER CREEK to dispose of or scrap unless otherwise written on this contract.

 

No work will be done or material furnished except as specified herein or agreed to in writing. Any modifications to this contract that change the cost, materials, work to be performed, or the estimated completion date must be made in writing and signed by all parties.

 

The winner has three (3) business days from this date to cancel this agreement. COPPER CREEK estimates the construction start date based on the production schedule. This is only an estimate. COPPER CREEK shall not be responsible for delays in either the starting date for the work or the substantial completion. Any delays caused by events beyond the control of COPPER CREEK shall not constitute abandonment and shall not be included in calculating time frames for payment or performance. COPPER CREEK is not responsible for delay or inability to perform caused by; acts of God, strikes, war, riots, shortages, weather conditions, public authorities, or other caused or conditions beyond its control or due to the buyer's conduct.

 

Winner agrees that title to the materials only passes to Winner under this agreement once said materials are paid in full. 

 

To the extent permitted by law, COPPER CREEK is not liable for incidental, special, or consequential damages. To the extent permitted by law, all of the Winner’s damages of an economic or commercial nature shall be limited to the purchase price. No warranty exists until the contract is paid in full. The manufacturer does offer a limited warranty on the materials sold and any and all claims by Winner for breach of warranty of any type for the materials must be brought directly against the manufacturer. Winner hereby waives any and all claims for breach of warranty against COPPER CREEK regarding the materials. The winner will be supplied with the warranty information from the manufacturer after payment for the completed work upon request. A specific copy of this warranty by the manufacturer is available upon request.

 

Severability: If any provision of this agreement shall be held invalid or unenforceable, the remainder of this agreement shall not be affected thereby and shall continue to be valid and shall be enforced to the fullest extent permitted by law.

Dispute Resolution: The venue for the resolution of any and all disputes arising under the Agreement shall be the Circuit Court of Champaign County, IL.

In the event of any dispute, claim, arbitration or litigation arising out of or relating to this contract, or the alleged breach thereof, the prevailing party shall be awarded its attorney's fees, expert witness fees, expenses, arbitration fees, and expenses, and court costs at the trial and all appellate levels; including costs and fees related to collection efforts.

bottom of page